Terms of Service

1. Acceptance of Terms

By accessing and using the Concrete Contractors of Denton website and services, you accept and agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our website or services.

2. Services Description

Concrete Contractors of Denton is a commercial and industrial general contractor specializing in concrete construction services throughout Denton County and North Texas. Our services include, but are not limited to:

• Tilt-wall construction
• Commercial foundations
• Parking lot concrete
• Industrial flatwork
• Concrete paving and site work
• Concrete repairs and restoration
• Retaining walls and structural concrete

All services are subject to written contracts that outline specific terms, conditions, pricing, and timelines for each project.

3. No Guarantees of Project Outcomes

While we strive to deliver quality concrete construction services, we make no guarantees, warranties, or representations regarding:

• Specific project outcomes beyond contracted specifications
• Exact project costs beyond contracted amounts (subject to change orders)
• Fixed timelines due to weather and site conditions
• The accuracy of preliminary estimates prior to contract

Every construction project is unique and subject to numerous variables including site conditions, weather, material availability, regulatory requirements, and unforeseen circumstances. Any project examples, testimonials, or performance claims shown on this website are for illustrative purposes only and do not guarantee similar results for your project.

4. Quotes and Estimates

Quotes and estimates provided through our website or by our representatives are preliminary and subject to change based on site conditions, project scope, and other factors. Final pricing will be provided in a written contract. Quotes are typically valid for 30 days from the date provided unless otherwise stated.

5. Project Contracts

All commercial concrete projects require a written contract that will include:

• Detailed scope of work
• Project timeline and milestones
• Payment terms and schedule
• Material specifications
• Warranty information
• Change order procedures

No work will commence until a signed contract and any required deposits are received.

6. Payment Terms

Payment terms will be specified in individual project contracts. Typically, commercial projects require a deposit upon contract signing, progress payments during construction, and final payment upon project completion. Late payments may incur additional fees as specified in the contract.

7. Project Changes and Delays

Changes to project scope, specifications, or timeline must be agreed upon in writing through a formal change order and may result in adjustments to pricing and completion dates. We are not responsible for delays caused by:

• Adverse weather conditions
• Client-requested changes or delays
• Unavailability of materials due to supply chain issues
• Site conditions that differ from those represented
• Acts of God or force majeure events
• Delays by other trades or contractors on site

8. Warranties and Guarantees

We warrant that all work will be performed in a professional and workmanlike manner consistent with industry standards. Specific warranty terms, including duration and coverage, will be detailed in individual project contracts. Warranties do not cover damage resulting from improper use, neglect, normal wear and tear, or conditions beyond our control such as soil movement or inadequate drainage not specified in our scope.

9. Limitation of Liability

To the maximum extent permitted by law, Concrete Contractors of Denton shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from or related to our services. Our total liability shall not exceed the total amount paid for the specific service giving rise to the claim.

10. Website Use

When using our website, you agree to:

• Provide accurate and current information in all forms
• Not use the website for any unlawful purpose
• Not attempt to gain unauthorized access to any part of the website
• Not transmit any viruses, malware, or harmful code
• Respect all intellectual property rights

11. Intellectual Property

All content on this website, including text, graphics, logos, images, and software, is the property of Concrete Contractors of Denton or its content suppliers and is protected by intellectual property laws. You may not reproduce, distribute, or create derivative works from this content without express written permission.

12. Dispute Resolution

Any disputes arising from these Terms of Service or our services will be resolved through good faith negotiation. If negotiation fails, disputes will be resolved through binding arbitration in Denton County, Texas, in accordance with the rules of the American Arbitration Association.

13. Governing Law

These Terms of Service are governed by and construed in accordance with the laws of the State of Texas, without regard to its conflict of law provisions.

14. Changes to Terms

We reserve the right to modify these Terms of Service at any time. Changes will be effective immediately upon posting to this page. Your continued use of our website and services after changes are posted constitutes acceptance of the modified terms.

15. Contact Information

For questions about these Terms of Service, please contact us: